Terms of Service

1. Acceptance of Terms

By accessing our website or engaging our Turnkey Online Casino Development services, you agree to be bound by these Terms of Service. If you do not agree to these terms, you should not use our services or access our website.

These terms apply to all visitors, clients, and any other parties who access or use our services. We reserve the right to update these terms at any time, and continued use of the services constitutes acceptance of any modifications.

2. Description of Services

We provide a Turnkey Online Casino Development service that includes, but is not limited to:

• A custom-built, cross-platform casino website
• Access to casino games from third-party providers including slots, live casino, and instant games
• Multi-currency and multi-language support
• Secure payment system and crypto payment integration
• Bonus engine, affiliate system, CRM, and marketing tools
• Website setup, branding, and deployment services

The specific scope of services delivered to each client is defined in the individual project agreement.

3. Client Obligations

By engaging our services, the client agrees to:

• Provide accurate and complete information during the onboarding process
• Obtain and maintain all necessary licenses and regulatory approvals for operating an online casino in their target jurisdictions
• Comply with all applicable laws, regulations, and industry standards related to online gambling
• Use the platform and services only for lawful purposes
• Not resell, sublicense, or redistribute our platform or services without written consent
• Respond to project communications in a timely manner to maintain the agreed delivery schedule

4. Project Delivery and Timeline

We aim to deliver turnkey casino projects within approximately three months from the start of the development process. However, the actual timeline depends on several factors, including:

• Completeness and timeliness of client-provided materials
• Design route chosen (template-based or custom design)
• Scope of additional payment integrations or custom adjustments
• Review and approval turnaround from the client

Estimated delivery dates are provided in good faith and are not binding guarantees. We will communicate any anticipated delays as early as possible.

5. Intellectual Property

5.1 Our Property

The platform, its underlying technology, architecture, codebase, tools, and proprietary systems remain the intellectual property of our company unless otherwise specified in the project agreement. Where source code transfer is included, the client receives the code and full rights as defined in the individual agreement.

5.2 Client Property

Any branding materials, logos, design assets, and content provided by the client remain the client's intellectual property. We will use such materials solely for the purpose of delivering the agreed services.

5.3 Game Content

Casino game content is provided by third-party developers and aggregators. All game intellectual property belongs to the respective game providers. Access to game content is subject to the terms and licensing conditions of those providers.

6. Payment Terms

Payment terms, pricing, and billing schedules are defined in the individual project agreement between the client and our company. General conditions include:

• Quotes are prepared based on the project scope discussed during the initial consultation
• Payment schedules may include upfront deposits, milestone payments, or recurring fees
• Late payments may result in service suspension or project delays
• All fees are non-refundable unless otherwise stated in the project agreement

7. Limitation of Liability

To the maximum extent permitted by law, we shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of or related to the use of our services. This includes, but is not limited to, loss of revenue, loss of data, business interruption, or loss of profits.

Our total liability for any claim arising from our services shall not exceed the total amount paid by the client under the applicable project agreement during the twelve months preceding the claim.

8. Warranties and Disclaimers

Our services are provided on an "as is" and "as available" basis. While we strive to deliver high-quality solutions, we make no warranties, express or implied, regarding:

• Uninterrupted or error-free operation of the platform
• Suitability of the platform for any specific regulatory jurisdiction
• The performance, availability, or conduct of third-party game providers or payment processors

9. Termination

Either party may terminate the service agreement according to the terms specified in the individual project contract. Upon termination:

• The client's access to the platform and associated tools may be discontinued
• Outstanding payments remain due and payable
• Client-owned branding and content assets will be returned upon request
• Confidential information of both parties must be returned or destroyed

10. Confidentiality

Both parties agree to keep confidential any proprietary, business, or technical information shared during the course of the engagement. This obligation survives the termination of the service agreement and applies to all employees, contractors, and agents of both parties.

11. Governing Law

These Terms of Service shall be governed by and construed in accordance with applicable international commercial law. Any disputes arising from these terms or the services provided shall be resolved through good-faith negotiation. If negotiation fails, disputes shall be submitted to binding arbitration in a mutually agreed jurisdiction.

12. Contact

For questions regarding these Terms of Service, please reach out through our contact page.